Terms of Service

Agreement to Terms

Welcome to StructureEdge Maricopa Decks. By using our website at www.maricopadecks.com or engaging our deck construction services, you agree to these Terms of Service. Please read them carefully before moving forward. If you do not agree with these terms, please do not use our website or services.

These terms apply to all visitors, users, and customers who access or use our services. We reserve the right to update or change these terms at any time. Your continued use of our website after any changes means you accept those changes.

Our Services

StructureEdge Maricopa Decks provides professional deck construction, repair, and related services in Maricopa, Arizona and surrounding areas. Our services include custom deck design and installation, composite and wood deck construction, deck repairs, replacements, railings, stairs, staining, sealing, and outdoor structures like pergolas and patio covers.

All services are provided subject to availability and acceptance by our team. We reserve the right to refuse service to anyone for any reason at any time. Project timelines, costs, and specifications will be outlined in a separate written contract or proposal for each project.

Quotes and Estimates

Any quotes or estimates provided by StructureEdge Maricopa Decks are for informational purposes only and are subject to change based on site conditions, material costs, and project scope. A formal written proposal will be provided before any work begins. You are not obligated to accept our proposal, and we are not obligated to perform work until a signed contract and deposit are received.

Estimates are valid for 30 days from the date issued unless otherwise specified. Material prices and labor costs may fluctuate, so we recommend scheduling your project as soon as possible after accepting a quote.

Payment Terms

Payment terms will be specified in your project contract. Typically, we require a deposit before work begins, with the balance due upon completion. We accept cash, check, and major credit cards. Late payments may be subject to interest charges or project delays.

If additional work is requested beyond the original scope, you will be notified of additional costs before that work is performed. Changes to the project scope may affect the final price and completion timeline.

Project Timeline and Delays

We will provide an estimated timeline for your project based on our current schedule and expected weather conditions. However, construction projects can be affected by weather, material availability, permit delays, and unforeseen site conditions. We will keep you informed of any delays and work to minimize disruptions to your schedule.

StructureEdge Maricopa Decks and its employees, contractors, and affiliates will not be liable for any indirect, incidental, or consequential damages arising from the use of our services or website. Our total liability is limited to the amount you paid for the specific service in question.

Warranties and Guarantees

We stand behind our work with a warranty on labor and workmanship as specified in your project contract. Material warranties are provided by the manufacturer and may vary by product. We will provide you with all relevant warranty information at the completion of your project.

Our warranty does not cover damage caused by improper use, lack of maintenance, natural disasters, or modifications made by others. Regular maintenance is your responsibility and is necessary to keep your deck in good condition.

Limitation of Liability

StructureEdge Maricopa Decks and its employees, contractors, and affiliates will not be liable for any indirect, incidental, or consequential damages arising from the use of our services or website. Our total liability is limited to the amount you paid for the specific service in question.

We carry general liability insurance and workers compensation insurance to protect you and our team during construction. In the unlikely event of property damage or injury, insurance claims will be handled according to standard insurance procedures.

Website Use and Content

The content on our website, including text, images, logos, and graphics, is owned by StructureEdge Maricopa Decks and is protected by copyright and trademark laws. You may not copy, reproduce, distribute, or use our content without written permission.

We strive to keep our website information accurate and up to date, but we do not guarantee that all information is current or error free. If you find incorrect information, please let us know so we can update it.

Privacy

Your privacy is important to us. Please review our Privacy Policy to understand how we collect, use, and protect your personal information.

Governing Law

These Terms of Service are governed by the laws of the State of Arizona. Any disputes arising from these terms or our services will be resolved in the courts of Maricopa County, Arizona.

Contact Us

If you have questions about these Terms of Service, please contact us: